The URL can be used to link to this page

Home My WebLink AboutStaff CommentsPlanning & Development Services (*tl"" 1101 Texas Avenue, P.O. Box 9960 College Station, Texas 77842 Ciry or Col.i,i:cr•. STATION Phone 979.764.3570 / Fax 979.764.3496 Home W7exnrA6M Unioerri MEMORANDUM February 15, 2013 TO: TMFIVE Properties, LLC via email: terrencerealtor@gmail.com FROM: Lauren A. Hovde, AICP, Staff Planner SUBJECT: TM5 Subdivision - Final Plat Staff reviewed the above -mentioned final plat as requested. The following page is a list of staff review comments detailing items that need to be addressed. If all comments have been addressed and the following information submitted on any Monday by 10:00 a.m., your project will be placed on the next available Planning and Zoning Commission meeting held in the City Hall Council Chambers, 1101 Texas Avenue. One (1) 24"x36" copy of the revised final plat; Parkland Dedication for duplexes will be assessed prior to the issuance of building permits; One (1) Mylar original of the revised final plat (required after Staff approval); and One (1) copy of the digital file of the final plat on diskette or e-mail to: pdsd ig italsu bmittaICa)cstx.gov. Upon receipt of the required documents for the Planning & Zoning meeting, your project will be considered formally filed with the City of College Station. Please note that this application will expire in 90 days from the date of this memo, if the applicant has not provided written response comments and revised documents to the Administrator that seek to address the staff review comments contained herein. Please note that a Mylar original of the revised final plat will be required after Staff approval and prior to the filing of the plat. If you have any questions or need additional information, please call me at 979.764.3570. Attachments: Staff Review Comments cc: Schultz Engineering, LLC via email: joeschultz84@verizon.net Case file #13-00900029 NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 1 of 3 STAFF REVIEW COMMENTS NO. 1 Project: TM5 SUBDIVISION (FP -MINOR) - 13-00900029 PLANNING 1. Structures that encroach into the setbacks of the proposed lot lines must be removed prior to filing the final plat for record at the court house. This s a condition of approval for the Minor Plat. 2. The Certificate of Planning and Zoning Commission needs to be replace with the Certificate of City Planner since the plat is being processed as a Minor Plat. 3. Though it appears there is not a file plat on record for these properties, please show the existing building plot configuration as if it were being processed as a replat. 4. The property line pop -out shown on the survey is not recognized by the Brazos County Appraisal District. Please contact BCAD to remedy the situation. 5. Parkland dedication will be assessed prior to the issuance of a building permit for each duplex. 6. Please label the streets on the vicinity map, show an update the submittal day, and revise the Certificate of Surveyor to match Section 8.8 of the UDO. 7. Please note that you may be required to submit paid tax certificates prior to the filing of your plat. Reviewed by: Lauren A. Hovde, AICP, Staff Planner Date: February 11, 2013 ENGINEERING COMMENTS NO. 1 1. Please add a 10-foot wide PUE along the rear of each proposed lot. 2. Show the lot corners tied to the City of College Station horizontal control monument. Reviewed by: Erika Bridges Date: February 14, 2013 ELECTRICAL COMMENTS REQUIRING IMMEDIATE ATTENTION SITE PLAN/PLAT: Developer will provide CSU with a digital, AutoCAD dwg format, version of plat and / or site plan as soon as it is available. Email to: wdavisa-cstx.gov LOAD DATA: The developer will provide load data to CSU as soon as it is available. This information is critical for CSU to accurately determine the size and number of transformers, and other equipment, required to provide service to the project. Failure to provide load data will result in construction delays and, due to clearance requirements, could affect the final building footprint. Delivery time for transformers and other equipment not in stock is approximate 26 weeks. EASEMENTS: The following easements will be required: • 5' PUE along Montclair Street frontage of all lots 5'PUE on each side of all interior lot lines • 5'PUE on west line of Lot 1 • 5PUE on east line of Lot 4 • 5'PUE along called common line of Lots 1&2, seconds E 101.21 feet • 5'PUE along called common line of Lots 3&4, seconds E for a distance of 81.14 feet. GENERAL ELECTRICAL COMMENTS that call being S48 degrees 02 minutes 47 that call being S48 degrees 13 minutes 45 1. Developer installs conduit per CSU specs and design. 2. CSU will provide drawings for electrical installation. NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 2 of 3 •Ie;;lwgns snolnaad ay; ul paaaMsue aaam s;uawwoo asagl '1991 ti f' l.g to aouelslp a aol 3 spuooas gb selnulw £I, saaabap gbS 6ulaq Ileo 1egl'1718£ slol;o cull uowwoo palled 61-101e 3nd,5 IGGJ l,Z' 1.01, 3 spuooas Lb solnulw ZO saaabap gbS aulaq Ileo 1egl'Z'86 slol bo Gull uowwoo papeo Ouole 3f1d,5 q lol to Gull ;sea uo 3nd,5 lol 10 Gull lsam uo 3f1d,9 scull lol aoualul Ile;o Gpls goes uo 3nd,9 s101 Ile }o 96e1uoa} laaalS ale101uoW 6uole 3fld ,g paalnbaa eq lllnn sluewesee 6ulnnollol aUl :S1N3W3SV3 '£ .pa;oN 'salaam gZ alewlxoidde sl Tools ul lou luewdlnbe aaglo pue saawao;sueal ao; awl; AaanllGO 'luladloo; 6ulppq leull agl loal;e pinoo 'sluawailnbei eoueaeolo of onp 'pue sAelop uollonilsuoo ul llnsel IIIM elep peol apinoid of smiled 'loefoid agl of eolnaas apinoid of paalnbaa 'luawdlnbe aGglo pue 'sjawao}sueal Io iegwnu pue ezls agl oupielop Aloleinooe of f1SO ao; leolwo sl uoilewaolul slgl 'algellene sl 11 se uoos se f1SO of elep peol apinad Ilp aadolanap agl :VIVO OVOI 'Z .pa;oN n00'x1sO@a slnepnn :01 Ilew3 'algellene sl li se uoos se ueld ails ao / pue leld;o uolsaan lewao; 6Mp db OolnV yel!O!p e gl!M f1SO apinad IIIM aadolanad :1Vld/NVId MIS ' 6 N0IIN311V 31VIa3WWl DNminom SiN3WWOO IVORI133I3/' .pa;oN 'pall; bulaq geld leUll agl of aoud pemwej aq of peau IIIM sand paleaaO Almou olui goeome Ilion golgnn sainlonils bullslxe Ile 'lenoidde Io uolllpuoo a sV"'I,k3 'Z WL yoaen Aepsinyl uo seBpuB e)I►a3 q;IM uo/;esianuoo I/ewe ue iad pa/}/aan seM paBuego slgl •;oI ay;;o aeaa ay;;e deB a sI away; os peBueyo sum slyl '3fld Bul;slxa ay; 4;Inn;ua3efpe;I omew o; gg Z s;ol;o aeaa ma Buole and jj-06 posodoid ay; anoua aseald 'slol agl;o aeei agl le paalnbaa sl Elnd 1I-O6 V (leodaa) -I, Z'ON S1N3WWOO ONRI33NION3 •pa;oN 'geld anoAjo Gulp; eql of aoud luaaano lou ae Aagl;l saleollipE)o xel pled llwgns of paalnbaa aq Aew noA legl e;ou aseald 'Z •pa;oaaaoo uaaq sey uol;eol !Poo slyl ,�Guueld AID,, ql!m 11 eoeldaa pue aeq einleu6ls n agl aapun legel „uewaleUO„ agl anowaa of Jauueld AID agl to aleol;llaaO aq; GslnaI, r ` °JNINNVId 6Z000600-£1 - WONIW-dd) NOISIn149f1S AHdunvy :loafad Z'ON S1N3WWOO MMAMI JAV1S lfmjaAiun PvTv sexal;o ewoH 6Z000600-£ } 'ou all; ase0 lau uozlaaA�)b9zllnyoseof :ilewe elA 0ql '6uuaaul6u3 zlinyoS :oo sluawwoo Malnaa;;elS :sluawyoelld 'OL9£'b9L'6L6 le aw lleo aseald 'uollewao;ul leuolllppe paau ao suollsanb AUe aney nog(;I -geld ayl;o 6uilil ayl of aoud pue lenoadde;;elS aaue paalnbei aq IIiM geld leul; paslAaa ayl;o leul6uo aeJAIN a leyl alou aseald z /Ao 'xlso'MMM//: lly •6ulleaw Z+Rd ayl;o Noon Oyl Aepuow uo alls qaM buimollo; ayl le poss000e aq ueo liodaa;;els pue epuebe ayl '6ullaaw Z'8d ayl ao; pelnpegos uaaq sey wall ano! aou0 ulaaay pouleluoo sluawwoo MalAaa ;;els aq ssaippe of Maas leyl jolealslulwpV ayl of sluawnoop paslAW pue sluawwoo asuodsai ualluM papinoid lou sey lueolldde ayl A 'owaw slyl;o alep ayl woa; sAep 06 ul aaldxa lilts uoileoildde slyl leyl alou aseald 'uollelS aballo0 to A1i0 ayl yliM pall; Allewio; paaaplsuoo aq illM loafoid anon( '6ulleaw 6uluoZ g 6uluueld ayl ao; sluawnoop paalnbei ayl;o }dhow uodn 'Ao 'xlso lelliwgnsleli ipsp of pew-9 jo alla�sip uo leld leUil ayl bo all; lelftp ayl to Adoo (6) au0 — pue'sllwaad 6uipllnq _ ;o aouenssl ayl of joud possesse aq lliM saxeldnp ao; uolleolpao puehljed '(lenoidde gelS aal;e paiinbei) geld leui; paslAaa ayl;o 1eul6uo aelAW (L) au0 'geld leUil paslAaa ayl;o Adoo „9£x„bZ (6) au0 anuanV sexal I OI [ 'sjagwey0 Ilouno0 IIeH A1i0 ayl ui play 6ullaaw uolsslwwo0 6uluoZ pue 6uluueld algeliene lxau ayl uo paoeld aq plM loefad ano! '-w,e 00 04 Aq AepuoW Aue uo pepwgns uoilewio;ul buimollo; ayl pue passaappe uaaq aney sluawwoo lie 11 •passaappe aq of paau leyl swab 6uille1ap sluawwoo MOIAOa ;;els;o lsil a sl abed 6ulMolio; ayl -palsenbei se geld leul; pauolluaw-anoge ayl paMalnaa;;elS leld leuld - NOISIAlaens AHdanW 103ronS aauueld;;elS'sJa608 esaJal MO83 WOO' 1!ew6@o Jolleaaaouaaaal :ilewa e1A 0ll 'salliedoid 3AI3Wl Ol £60Z'9 yoaew Wn4NVUOW3W 96b£'b9L'6L6 Xe3 / OL9£179L'6L6 auoyd Zb9LL sexes 'uollelS 9691100 0966 xO9 •O•d 'anuanV sexal 6066 ,Tiruart�up W� y rvxa� fv aruoy If;!saaniun /N-gy sexal 10 awoH U0Z '9 gORIN :a;ep slneQ.uoplaM :Aq pannalnad Gb sa;nulw Zo sa9.l69p 917S 6uIeq Ileo Legl'Z'8L s}o-; L scull 101 Jolia;ul s;ol Ile;o a6e;ua;;aaa; paalnbei aq 1pm s;uawasee 6uole 3nd.9 • ma uo 3nd,9 • :aM'uo 3nd,9 • )ee uo 3nd,9 • buole 3nd,9 • I1SS.MMS`d3 '£ 'Z uolsJaA';ewjo; 6nnp QyOo;ny 'ie;161p e q}Inn n30 apinoJd lIinn Jadolanaq :IV"Id/NV-ld 13119 `L N011N311V nVIa3WW1 JN1211ntm S1N3WWOO IV31HI3313 £ L0Z 'b goJeW :a;ea sa6pu8 e� pu ] :Aq pannalnab pa!!; bulaq;eld leul; ag; o; Joud panowaJ eq o; peau pinn s3nd pa;ewo Alnnau o;ul goeoJoue pIM go14nn saanonJ;s bul;slxe Ile 'lenadde ;o uoi;lpuoo a sV•"I.13 'Z 'and 6ul;slxa ay; LI Inn;uaoefpe u eiew o; g+g Z sm;o aeaa ay; 6uole and 74-0l posodoid ay; anow aseald 's;ol ag;;o Jew ag;;e paalnbaa sl 3nd;1-0L `d (;eadaa) I Z 'ON S1N3WWO3 ONIH33NION3 £ Wz '9 goJeW :ale(] saa6oa esaaal :Aq pannalnaa ;eld JnoA;o 6upg ag; o; Joud ;uaJJno ;ou we Aag;;l sa;eol;l;Jao xe; pled ;lwgns o; paJlnbaJ aq /ew noA leq; a;ou aseald 'Z ,Jauueld Al!o,, g;lnn;l eoeldej pue Jeq aJn;eu6ls aq; Japun lagel „uewneg0„ aq; anowaJ o; Jauueid A;!o aq; ;o a;e01111J90 ag; aslnab L 6Z000600-EL - WONIW-d3) NOISInIOBnS Md2jnW ;OafoJd Z 'ON S1N3WWOO M31A3M ddt/1S .pa;off/ •sMaaM gZ alewlxoidde sl Mools u1 lou luawdlnbe aaylo pue sjawn1suml ao; awl; laanllad •lu idloo; bulpllnq leull aqj loage P1noo 'sluawaalnbei soueaeelo of anp 'pue sxelep uollonalsuo0 ut llnsaa IIIM elep peol apinoad of aanlled •loefoid ay; 01 901AJGS apinoad of paalnbai 'luewdmbe aaylo pue 'saawao;sueal ;o aagwnu pue ozls a41 oulwaalap Alalemooe of NS0 ao; leolwo s1 uo1lewao;ui slu 'algellene sl 1I se uoos se N80 of elep peol apinoad IIIM aadoleAep a41 :V1V0 OVOI 'Z .pa#oN A06•x1s0@a slAepM :o1 IIew3 •aigellene sl 1! se uoos se ueld ails ao / pue 1eld;o uolsaaA 'lewao; 6Mp ab'Oolnb '1e116ip e qi!m NSO apinoad IIIM jadolana4 :1Vld/NVId MIS ' 6 N01IN311V 31VIa3WWl ONmint 3» S1N3WWO3 IVOIN13313 •luawnuow laluoo leluozuoq uollelS oballoO;o A110 au} of pal; siawoo 1ol ay; Mogs •Z •pappe uaaq sey 3nd ay1 •1ol pasodoad Wea;0 Jeaa aril buole and 9p1M 1001-0 b e ppe aseald • I. 4'ON S1N3WW00 ON11133NION3 .pa;oN •;eld anoR;o 6uflld otl; o; aolad sa;eol;lao xe; pled;lwgns o; paalnbei eq Aew noA 4e; a;ou aseald L/I •pa;epdn uaaq sey a;eoy!poo saoAeAjng ey; pue S60Z Ajenagad saes mou a;ep le;;lwgns ayl •pappe uaaq aney slage/;aaa;s ayl ,ocin ay;;o 9.9 uolloaS golew of aoAeAanS;o aleollllaa0 ay} aslnaa 'Aep 'dew /. -9/ pue lelllwgns ay} a;epdn ue Mogs �(11u101A 041 uo s}aaJls ay; loge) aseald .pa;oN •xeldnp goea ao; llwaad 6u1P11nq e;o aouenssl ay} of joud possasse aq 111M uolleolpop puehlaed •9 f •;eld ay; yo;ew o; Bulddew clay; paBuego aney Aotp pue Bulddew clay; ;aaajoo o; way; ao; GVOg o; pepinoad uaaq aney speep pue AeAjns eyl •uogenl1s a41 Apawai of py0g loeluoo aseald •loujsl4 lesleaddV Aluno0 sozea9 ayl Aq pazlubmaa lou s1 Aanans ayl uo uMoys lno-dod cull Aliadad a41 'bt� •;eld ey; o; pappe uaaq sey uogeanBl;uoa;old Bulpllnq Bul;slxe ayl •leldaa a se pass000id bu1aq aaaM lI bI se uollean6l;uoo fold 6u1pllnq bu1ls1xe aril Mogs aseald 'salliedoad asegj ao; piom uo leld all; a lou s1 aaayl sieedde 11 y6noU1 '£/ •pa6ueyo uaaq sey uogeoltjpjoa sill geld aou11N a se pass000id 6uieq s1 leld all souls aauueld A1I0 do aleollllia0 aril 41IM ooeldaa aq of speau uolsslwwo0 6uluoz pue buluueld 10 aleol;l1aa0 a4I 'Z (�] •s-/oeq;as ay; o;ul yoeoaoue;ou saop `; yaolg `ti;ol pasodoad `slabMOR k06;e pa;eao/ ein;ona;s Bul;slxe eq; a;ou aseald •pe;old •leld aoullN a41 ao; lenoidde;o uo111puoo e s s1t11 •asnoq lanoo aril le prom ao; leld leul; ay16u1Q; of aoud panowaa aq lsnw sou111ol pasodoad ayl;o s�oeglas a41 olul goeoaoua letll saanlonalS 0NINNVId 6Z000600-£ 6 - WONIW-dd) N0ISIAI49f1S 9W1:10af0ad 4 'ON S1N3WW00 M3IA3a 33V1S .pa;aN �oafoad sly y�lM Flo sl uol�e�lueg 1A NOIIVIIN dS .pa;oN 'LZ09'b9L'6L6 1e Shea uoplaM joeluoo eseeld s;uawwoo leou}OGiG Gnoge Gyj;o Aue ssnoslp of '6 .pa;oN 'nsO Aq pau6lsap se 6uilnoi Ilnpuoo pue 'suol}eool Najaw lie 'sNeebgo;!Ms No 'saxoq llnd 'SJGWJO;sueN} •a•l 'GOINGS leouAOalG GpinoNd of AGesseoeu salplloej leoploole posodoid lie Moys asnw ueld a}ls leUld •9 .pa;oN •nsO Aq paphoNd sle}saped Aiepuooes pue saxoq llnd 'u6lsap pue soads nsO Ned slelseped Aiepuooes pue saxoq llnd sllelsu! Nadolanad •L .pa;oN •u6lsap pue soads nsO Nad 'aolnap Nay;o No 'saxoq land 'sNawNo;sueN} -G•l 's6ugoo; No sped aolnap OlN)oala sNnod NadolanGd •9 •pa;ON •jnoAel leouioala nsO uo uMoys se j!npuoo llelsui pue ys!uNn} IIIM Nadolanap 'SGOlnap 6ui)Slxe Naylo No NawNo;sueNl pa;eu6!sop }e Islxe jou seop I!npuoo }I •9 .pa;oN •paN!nboi se puGjxa pue saohap bu!;slxe Naylo No sNawNo;sueNl pa;eu6lsop Is Ilnpuoo 6ullslxe IdeoNaju! IIIM NadolanGd b .pa;oN •NaslN sneisul nsO •Ilnpuoo Nasu yoea No} Ilnpuoo OWI No pl6lN;o ,0E SapinoNd Nadolanad •£ .pa;oN •uo!;epe}sul leolN1001a JOI S6ulMeNp apinoid IIIM nsO 'Z .pa;oN u6lsap pue soads nsO Nad;!npuoo sllelsul Nadolanaa • 1, i S1N3WWOO IVORI103131V213N30 / 'and ,Ob uI papMOul '1991 b l,' 19 Jo aoue;slp a No; 3 spuooas 9V sainulw £1 sawbap gbs 6ulaq PO ley} 'ti+gg s}ol Jo Gull uowwoo palleo 61-10le 3nd,9 •/ 'and ,OL 14 papnPul 199J IZ' 101 3 spuooas Lti salnulw Z0 seei6ep gbS 6ulaq Ileo ley} `Z'81 s}ol;o cull uowwoo palleo 6uole 3f1d,9 • 1' •pappe uaaq aney s;uaeuasea ayl ti;ol;o Gull isea uo 3ftd,g • •pappe uaaq aney s;uawesee ayl 1 iol;o Gull isaM uo 3(1d,9 • •pappe uaaq aney s;uawasea ayl seu!l lol Nouaiul Ile {o epls yoea uo 3fld,g •� pappe uaaq aney s;uawasee eyl s}ol ile;o ebeluoN; iaaNis NleloiuoW 6uole 3fld ,9 • A paNlnbej eq ll!M sivawasee buIMOliOJ Gyl :SIN3W3SV3 T £ )o E MainaJ Mau Alojeldwoo a a}n1psuoo jj!m'Aj!o aqa of ino paluiod uaaq IOU anew jegl sueld asegj uo sa6uego eu011ippe buy sueld jnoA uo „paIggnq„ pue japal lepwsmi Vou jno! ui pouieldxa aq isnw 'uoiaeag 9691loo jo �1!3 aqj Aq paisanbw uaaq you aneq Jegi 'sueld aqa of apew sabMgo Auy :310N £60Z'9Aaenagaj :ale(] £60Z '9 Ajenagaj :ale(] e!}naan Ahem :Aq paMalnab •joafoad s!gj g;!M No s! uo!lej!ueS 6 NOIIVIIN`dS slnep uoplaM :Aq pannalnab 'LZ09'b9L'6L6 le sloe(] uoplaM }oefuoo aseald s;u9ww00 le0140919 anoge ay; jo !ue ssnos!p of •nso Aq pau6!sop se 6ugna }!npuoo pue 'suo!leool jejew Ile 'saea6goj!Ms ao 'saxoq IInd 'sjawjo;sues; •e ! 'eOIAJeS Ie0u10919 ap!nojd o; Ajussaoeu sa!j!I!oe} leoploala posodoid Ile Mogs Isnw veld aj!s leuij *nso Aq Pep!noid slelsoped Aiepuooes pue saxoq Ilnd 'u6!sap pue soads nso aad sleasapad laepuooes pue saxoq Ilnd slle;su! aadolanaa •u6!sap pue soads Aso aad 'aOlnap aaq!o ao 'saxoq lInd 'saawjojsuea; -a-! 'sbugool ao sped aOlnap ou;oele sinod aadolanaa Ino4el lewioala Aso uo uMogs se;!npuoo pe}sui pue gs!uan; II!m aadolanap 's901nap 6u11slxa aag;o ao aawaolsuea; pa}eu6!sap ;e ;s!xe ;ou seop a!npuoo ;i •paa!nbaa se puaJxa pue saOlnap bu!;s!xe jeq;o jo siewjojsuejl pe;eu6!sap le;mpuoo 6ugs!xe jdawa}u! II!M aadolanap aasu spe;sul Aso fmpuoo aasu qoea ao; a!npuoo oWI jo p!61a Jo ,0£ sap!noid aadolanap R 9 .9 saainaasnap/noR'uasa 96!1 :: h91/' 6G1i 'X V l ` OL.Sti'79L'6L6 'IH.I. i9S'L1 • S�X3.1_ • NOI IG i SFL'J".3I'A?J • HIIN ANI SVX_11, LOl l • 0966 XOU 'O d saormras;rraurdopanaQ,cri Rurzexrbjzr 6Z000600-£ 4 'ou ON aseO ,,l? ;au'uozuan@a ggzjingosaof :eln '011 '6uuaeul6u3 ziingoS '-3 d 'zlingoS aof :Od 'Malnaa alaui JOI �GGM }xau jjejs 01 pa;ngpjslp eq IIIM joefoid slUl 'uolfeolldde HONIW - 1Vld IVNld ano! jo lelllwgns aqj Aoj noA �uegl leld JOUIN — uolslNpgnS 9Wl aoirsns Mueld ledlaulad j dOIV 'IjagngoS uosef :NOHJ "X— woo'llew6@aojleaHaouaaaal 'O�-j 'saliaadoad 3NdWl 'ao}leab aouaaaal :Ol £ bOZ ' 6 laenagad wnONVEOW3W Alsidalun yv-,OV ruxay fo aumH NOI NTIS HJHnnIOD AO ll:) -,r (* F4" CITY OF COLLEGE STATION Homr ofT AdM U.ro ,,- MEMORANDUM February 1, 2013 TO: FROM: Jason Schubert, AICP Principal Planner SUBJECT: TM5 SUBDIVISION (FP -MINOR) Thank you for the submittal of your FINAL PLAT - MINOR application. This project will be distributed to staff next week for their review. cc: Case file no. 13-00900029 Pkxxixg &Deve%pmmt Services P.O. BOX 9960 • 1101 TEXAS AVENUE • COLLEGE STATION • TEXAS • 77942 TEL. 979.764.3570 • FAX. 979.764.3496 csa.go idmervims (* 01F,41 CITY OF COLLEGE STATION Hom ofT.At4MU.,.,y- MEMORANDUM February 1, 2013 TO: Terrence Realtor, TMFIVE Properties, LLC; TerrenceRealtor@gmail.com FROM: Jason Schubert, AICP Principal Planner SUBJECT: PC: Joe Schultz, P.E., Schultz Engineering, LLC; via: joeschultz84@verizon.net Planing &Deve%pmmt Services P.O. BOX 9960 • 1101 TEXAS AVENUE • COLLEGE STATION • TEXAS • 77942 TEL. 979.764.3570 • PAX. 979.764.3496 csa.gov/Aevservims (* F"" CITY OF COLLEGE STATION Hom ofT.At4MU.'.ty- MEMORANDUM February 1, 2013 TO: Terrence Realtor, TMFIVE Properties, LLC; TerrenceRealtor@gmail.com FROM: Jason Schubert, AICP Principal Planner SUBJECT: TM5 Subdivision — Minor Plat Thank you for the submittal of your FINAL PLAT - MINOR application. This project will be distributed to staff next week for their review. PC: Joe Schultz, P.E., Schultz Engineering, LLC; via: joeschultz84@venzon.net Case file no. 13-00900029 Pkxxixg &Deve%pmmt Services P.O. BOX 9960 • 1101 TEXAS AVENUE • COLLEGE STATION • TEXAS • 77942 TEL. 979.764.3570 • PAX. 979.764.3496 csa.govidmervims ELECTRICAL COMMENTS REQUIRING IMMEDIATE ATTENTION SITE PLAN/PLAT: Developer will provide CSU with a digital, AutoCAD dwg format, version of plat and / or site plan as soon as it is available. Email to: wdavis(cDcstx.gov LOAD DATA: The developer will provide load data to CSU as soon as it is available. This information is critical for CSU to accurately determine the size and number of transformers, and other equipment, required to provide service to the project. Failure to provide load data will result in construction delays and, due to clearance requirements, could affect the final building footprint. Delivery time for transformers and other equipment not in stock is approximate 26 weeks. EASEMENTS: The following easements will be required: 5' PUE along Montclair Street frontage of all lots 5'PLIE on each side of all interior lot lines 5'PLIE on west line of Lot 1 5'PLIE on east line of Lot 4 5'PLIE along called common line of Lots 1&2, that call being S48 degrees 02 minutes 47 seconds E 101.21 feet 5'PLIE along called common line of Lots 3&4, that call being S48 degrees 13 minutes 45 seconds E for a distance of 81.14 feet. GENERAL ELECTRICAL COMMENTS 1. Developer installs conduit per CSU specs and design. 2. CSU will provide drawings for electrical installation. 3. Developer provides 30' of rigid or IMC conduit for each riser conduit. CSU installs riser. 4. Developer will intercept existing conduit at designated transformers or other existing devices and extend as required. 5. If conduit does not exist at designated transformer or other existing devices, developer will furnish and install conduit as shown on CSU electrical layout. 6. Developer pours electric device pads or footings, i.e. transformers, pull boxes, or other device, per CSU specs and design. 7. Developer installs pull boxes and secondary pedestals per CSU specs and design, Pull boxes and secondary pedestals provided by CSU. 8. Final site plan must show all proposed electrical facilities necessary to provide electrical service, i.e. transformers, pull boxes, or switchgears, all meter locations, and conduit routing as designed by CSU. 9. To discuss any of the above electrical comments please contact Weldon Davis at 979.764.5027. Reviewed by: Weldon Davis Date: 2.6.13 SANITATION 1. Sanitation is ok with this project. Reviewed by: Wally Urrutia Date: February 6, 2013 ENGINEERING COMMENTS NO. 1 1. Please show the original and replatted lots. (Are these platted lots? GIS shows them as platted, but I can't locate the original plat.) 2. Please be aware that the existing structures will encroach into newly created setbacks and easements and will need to be approved on the condition that they be demolished or moved before filing of the plat. 3. A 10-ft PUE is required at the rear of the lots. 4. Show the lot corners tied to the City's horizontal control monuments. Reviewed by: Erika Bridges Date: 2/14/13 (*Or1 CITY OF, COLLAGE STATION Home afTexz A&M University" Planning & Development Services 1101 Texas Avenue, P.O. Box 9960 College Station, Texas 77842 Phone 979.764.3570 / Fax 979.764.3496 MEMORANDUM TO: FROM: SUBJECT: Tm5 Subdivision - Final Plat Staff reviewed the above -mentioned final plat as requested. The following page is a list of staff review comments detailing items that need to be addressed. If all comments have been addressed and the following information submitted on any Monday by 10:00 a.m., your project will be placed on the next available Planning and Zoning Commission meeting held in the City Hall Council Chambers. 1101 Texas Avenue. One (1) 24"x36" copy of the revised final plat; Parkland Dedication for duplexes will be assessed prior to the issuance of building permits; One (1) Mylar original of the revised final plat (required after P&Z approval); and One (1) copy of the digital file of the final plat on diskette or e-mail to: pdsdigitalsubmittal(cDcstx.gov. Upon receipt of the required documents for the Planning & considered formally filed with the City of College Station. expire in 90 days from the date of this memo, if the applicant comments and revised documents to the Administrator that Zoning Please meeting, your project will note that this application has not provided written respo be will nse seek to address the staff review comments contained herein. If all comments have not been addressed your project will not be scheduled for a Planning & Zoning Commission meeting. Your project may be placed on a future agenda once all the revisions have been made and the appropriate fees paid. Once your item has been scheduled for the P&Z meeting, the agenda and staff report can be accessed at the following web site on Monday the week of the P&Z meeting. http://www.csb(.gov/pz Please note that a Mylar original of the revised final plat will be required after P&Z approval and prior to the filing of the plat. If you have any questions or need additional information, please call me at 979.764.3570. Attachments: Staff Review Comments cc: Case file #13-00900029 STAFF REVIEW COMMENTS NO. 1 Project: TM5 SUBDIVISION (FP -MINOR) - 13-00900029 PLANNING 1. Structures that encroach into the proposed lot lines' setbacks must be removed prior to filing the final plat for record at the court house. 2. Please add a 10-foot wide PUE along the rear of each proposed lot. 3. The Certificate of Planning and Zoning Commission needs to be replace with the Certificate of City Planner since the plat is being processed as a Minor Plat. 4. Though it appears there is not a file plat on record for these properties, please show the existing building plot configuration as if it were being processed as a replat. 5. The property line pop -out shown on the survey is not recognized by the Brazos County Appraisal District. 6. Parkland dedication will be assessed prior to the issuance of a building permit for each duplex. 7. Please label the streets on the vicinity map, show a City of College Station control monument, update the submittal day, and revise the Certificate of Surveyor to match Section 8.8 of the UDO. 8. Please note that any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that the City has not been made aware of will constitute a completely new review. 9. Please note that you may be required to submit paid tax certificates prior to the filing of your plat. Reviewed by: Lauren A. Hovde, AICP, Staff Planner Date: February 11, 2013 (*0"l CITY OF, COIS,IIGE .STATION Home afTexz A&M University TO: FROM: Planning & Development Services 1101 Texas Avenue, P.O. Box 9960 College Station, Texas 77842 Phone 979.764.3570 / Fax 979.764.3496 MEMORANDUM SUBJECT: Tm5 Subdivision (Fp-Minor) - Final Plat TM5 SUBDIVISION (FP -MINOR) Oust a "bookmark) «Tm5v Staff reviewed the above -mentioned final plat as requested. The following page is a list of staff review comments detailing items that need to be addressed. If all comments have been addressed and the following information submitted by Monday, , 10:00 a.m., your project will be placed on the next available Planning and Zoning Commission meeting held in the City Hall Council Chambers, 1101 Texas Avenue. One (1) 24"x36" copy of the revised final plat; Thirteen (13) 1 Vx17" copies of the revised final plat (IF GOING TO P&Z); Parkland Dedication in the amount of $ must be submitted prior to the filing of the final plat; Easement Dedication Sheet for Temporary Turnaround (delete if not applicable); One (1) Mylar original of the revised final plat (required after P&Z approval); and One (1) copy of the digital file of the final plat on diskette or e-mail to: pdsdigitalsubmittal(cDcstx.gov. Upon receipt of the required documents for the Planning & Zoning meeting, your project will be considered formally filed with the City of College Station. Please note that this application will expire in 90 days from the date of this memo, if the applicant has not provided written response comments and revised documents to the Administrator that seek to address the staff review comments contained herein. If all comments have not been addressed your project will not be scheduled for a Planning & Zoning Commission meeting. Your project may be placed on a future agenda once all the revisions have been made and the appropriate fees paid. Once your item has been scheduled for the P&Z meeting, the agenda and staff report can be accessed at the following web site on Monday the week of the P&Z meeting. http://www.csb(.gov/pz Please note that a Mylar original of the revised final plat will be required after P&Z approval and prior to the filing of the plat. If you have any questions or need additional information, please call me at 979.764.3570. NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 3 of 8 Attachments: Staff Review Comments cc: Case file #13-00900029 NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 4 of 8 STAFF REVIEW COMMENTS NO. 1 Project: TM5 SUBDIVISION (FP -MINOR) - 13-00900029 PLANNING 10. Please note that any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that the City has not been made aware of will constitute a completely new review. 11. A temporary turnaround is required at (specific location) for Fire and Sanitation services: • An Easement Dedication Sheet and all necessary attachments must be submitted for review prior to the final plat being scheduled for a P&Z meeting; • The Temporary Turnaround Easement must be filed at the courthouse and the recording information included on the Final Plat prior to the plat being filed at the courthouse. 12. Please note that you may be required to submit paid tax certificates if they are not current prior to the filing of your plat. 13. The construction documents and reports are still under review and may affect the plat. 14. Please be aware that each lot will be required to provide a minimum of two (2) trees of at least two inches (2") in caliper or one (1) tree of four inch (4") caliper per Ordinance No. 3222. Reviewed by: PZPLNM Date: (*0"l CITY OF, COIS,IIGE .STATION Home afTexz A&M University TO: FROM: Planning & Development Services 1101 Texas Avenue, P.O. Box 9960 College Station, Texas 77842 Phone 979.764.3570 / Fax 979.764.3496 MEMORANDUM SUBJECT: Tm5 Subdivision (Fp-Minor) - Final Plat TM5 SUBDIVISION (FP -MINOR) Oust a "bookmark) «Tm5v Staff reviewed the above -mentioned final plat as requested. The following page is a list of staff review comments detailing items that need to be addressed. If all comments have been addressed and the following information submitted by Monday, , 10:00 a.m., your project will be placed on the next available Planning and Zoning Commission meeting held in the City Hall Council Chambers, 1101 Texas Avenue. One (1) 24"x36" copy of the revised final plat; Thirteen (13) 1 Vx17" copies of the revised final plat (IF GOING TO P&Z); Parkland Dedication in the amount of $ must be submitted prior to the filing of the final plat; Easement Dedication Sheet for Temporary Turnaround (delete if not applicable); One (1) Mylar original of the revised final plat (required after P&Z approval); and One (1) copy of the digital file of the final plat on diskette or e-mail to: pdsdigitalsubmittal(cDcstx.gov. Upon receipt of the required documents for the Planning & Zoning meeting, your project will be considered formally filed with the City of College Station. Please note that this application will expire in 90 days from the date of this memo, if the applicant has not provided written response comments and revised documents to the Administrator that seek to address the staff review comments contained herein. If all comments have not been addressed your project will not be scheduled for a Planning & Zoning Commission meeting. Your project may be placed on a future agenda once all the revisions have been made and the appropriate fees paid. Once your item has been scheduled for the P&Z meeting, the agenda and staff report can be accessed at the following web site on Monday the week of the P&Z meeting. http://www.csb(.gov/pz Please note that a Mylar original of the revised final plat will be required after P&Z approval and prior to the filing of the plat. If you have any questions or need additional information, please call me at 979.764.3570. NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 6 of 8 Attachments: Staff Review Comments cc: Case file #13-00900029 NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 7 of 8 STAFF REVIEW COMMENTS NO. 1 Project: TM5 SUBDIVISION (FP -MINOR) - 13-00900029 PLANNING 15. Please note that any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that the City has not been made aware of will constitute a completely new review. 16. A temporary turnaround is required at (specific location) for Fire and Sanitation services: • An Easement Dedication Sheet and all necessary attachments must be submitted for review prior to the final plat being scheduled for a P&Z meeting; • The Temporary Turnaround Easement must be filed at the courthouse and the recording information included on the Final Plat prior to the plat being filed at the courthouse. 17. Please note that you may be required to submit paid tax certificates if they are not current prior to the filing of your plat. 18. The construction documents and reports are still under review and may affect the plat. 19. Please be aware that each lot will be required to provide a minimum of two (2) trees of at least two inches (2") in caliper or one (1) tree of four inch (4") caliper per Ordinance No. 3222. Reviewed by: PZPLNM Date: (*011r1 CITY OF, COIS,IIGE .STATION Home afTexz A&M University February 15, 2013 Planning & Development Services 1101 Texas Avenue, P.O. Box 9960 College Station, Texas 77842 Phone 979.764.3570 / Fax 979.764.3496 MEMORANDUM TO: TMFIVE Properties, LLC via email: terrencerealtor@gmail.com FROM: Lauren A. Hovde, AICP, Staff Planner SUBJECT: TM5 Subdivision - Final Plat Staff reviewed the above -mentioned final plat as requested. The following page is a list of staff review comments detailing items that need to be addressed. If all comments have been addressed and the following information submitted on any Monday by 10:00 a.m., your project will be placed on the next available Planning and Zoning Commission meeting held in the City Hall Council Chambers. 1101 Texas Avenue. One (1) 24"x36" copy of the revised final plat; Parkland Dedication for duplexes will be assessed prior to the issuance of building permits; One (1) Mylar original of the revised final plat (required after Staff approval); and One (1) copy of the digital file of the final plat on diskette or e-mail to: pdsdigitalsubmittal(cDcstx.gov. Upon receipt of the required documents for the Planning & Zoning meeting, your project will be considered formally filed with the City of College Station. Please note that this application will expire in 90 days from the date of this memo, if the applicant has not provided written response comments and revised documents to the Administrator that seek to address the staff review comments contained herein. Please note that a Mylar original of the revised final plat will be required after Staff approval and prior to the filing of the plat. If you have any questions or need additional information, please call me at 979.764.3570. Attachments: Staff Review Comments cc: Schultz Engineering, LLC via email: joeschultz84@verizon.net Case file #13-00900029 NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 1 of 3 STAFF REVIEW COMMENTS NO. 1 Project: TM5 SUBDIVISION (FP -MINOR) - 13-00900029 PLANNING 1. Structures that encroach into the setbacks of the proposed lot lines must be removed prior to filing the final plat for record at the court house. This s a condition of approval for the Minor Plat. 2. The Certificate of Planning and Zoning Commission needs to be replace with the Certificate of City Planner since the plat is being processed as a Minor Plat. 3. Though it appears there is not a file plat on record for these properties, please show the existing building plot configuration as if it were being processed as a replat. 4. The property line pop -out shown on the survey is not recognized by the Brazos County Appraisal District. Please contact BCAD to remedy the situation. 5. Parkland dedication will be assessed prior to the issuance of a building permit for each duplex. 6. Please label the streets on the vicinity map, show an update the submittal day, and revise the Certificate of Surveyor to match Section 8.8 of the UDO. 7. Please note that you may be required to submit paid tax certificates prior to the filing of your plat. Reviewed by: Lauren A. Hovde, AICP, Staff Planner Date: February 11, 2013 ENGINEERING COMMENTS NO. 1 1. Please add a 10-foot wide PUE along the rear of each proposed lot. 2. Show the lot corners tied to the City of College Station horizontal control monument. Reviewed by: Erika Bridges Date: February 14, 2013 ELECTRICAL COMMENTS REQUIRING IMMEDIATE ATTENTION SITE PLAN/PLAT: Developer will provide CSU with a digital, AutoCAD dwg format, version of plat and / or site plan as soon as it is available. Email to: wdavis(c-cstx.gov LOAD DATA: The developer will provide load data to CSU as soon as it is available. This information is critical for CSU to accurately determine the size and number of transformers, and other equipment, required to provide service to the project. Failure to provide load data will result in construction delays and, due to clearance requirements, could affect the final building footprint. Delivery time for transformers and other equipment not in stock is approximate 26 weeks. EASEMENTS: The following easements will be required: • 5' PUE along Montclair Street frontage of all lots • 5'PUE on each side of all interior lot lines • 5'PUE on west line of Lot 1 • 5'PUE on east line of Lot 4 • 5'PUE along called common line of Lots 1&2, that call being S48 degrees 02 minutes 47 seconds E 101.21 feet • 5'PUE along called common line of Lots 3&4, that call being S48 degrees 13 minutes 45 seconds E for a distance of 81.14 feet. GENERAL ELECTRICAL COMMENTS Developer installs conduit per CSU specs and design. CSU will provide drawings for electrical installation. NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 2 of 3 3. Developer provides 30' of rigid or IMC conduit for each riser conduit. CSU installs riser. 4. Developer will intercept existing conduit at designated transformers or other existing devices and extend as required. 5. If conduit does not exist at designated transformer or other existing devices, developer will furnish and install conduit as shown on CSU electrical layout. 6. Developer pours electric device pads or footings, i.e. transformers, pull boxes, or other device, per CSU specs and design. 7. Developer installs pull boxes and secondary pedestals per CSU specs and design, Pull boxes and secondary pedestals provided by CSU. 8. Final site plan must show all proposed electrical facilities necessary to provide electrical service, i.e. transformers, pull boxes, or switchgears, all meter locations, and conduit routing as designed by CSU. 9. To discuss any of the above electrical comments please contact Weldon Davis at 979.764.5027. Reviewed by: Weldon Davis Date: February 6, 2013 SANITATION 1. Sanitation is ok with this project. Reviewed by: Wally Urrutia Date: February 6, 2013 NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 3 of 3 ENGINEERING COMMENTS NO. 2 1. (Repeat) A 10-ft PUE is required at the rear of the lots. Please move the proposed 10-ft PUE along the rear of lots 2 U to make it adjacent with the existing PUE. 2. FYI ... As a condition of approval, all existing structures which will encroach into newly created PUEs will need to be removed prior to the final plat being filed. Reviewed by: Erika Bridges Date: 3/4/13 (_ 4IW4� CITY OF COI7.F.GF. STATION Home ofTe A&M Unioeaity' 1101 Texas Avenue, P.O. Box 9960 College Station, Texas 77842 Phone 979.764.3570 / Fax 979.764.3496 MEMORANDUM March 6, 2013 TO: TMFIVE Properties, LLC via email: terrencerealtor@gmail.com FROM: Teresa Rogers, Staff Planner SUBJECT: MURPHY SUBDIVISION - Final Plat Staff reviewed the above -mentioned final plat as requested. The following page is a list of staff review comments detailing items that need to be addressed. If all comments have been addressed and the following information submitted on any Monday by 10:00 a.m., your project will be placed on the next available Planning and Zoning Commission meeting held in the City Hall Council Chambers. 1101 Texas Avenue. One (1) 24"x36" copy of the revised final plat; One (1) Mylar original of the revised final plat (required after Staff approval); Parkland Dedication for duplexes will be assessed prior to the issuance of building permits; and One (1) copy of the digital file of the final plat on diskette or e-mail to pdsdigitalsubmittal(cDcstx.gov. Upon receipt of the required documents for the Planning & considered formally filed with the City of College Station. expire in 90 days from the date of this memo, if the applicant comments and revised documents to the Administrator that Zoning Please meeting, your project will note that this application has not provided written respo seek to address the staff rev be will nse iew comments contained herein. Once your item has been scheduled for the P&Z meeting, the agenda and staff report can be accessed at the following web site on Monday the week of the P&Z meeting. http://www.csb(.gov/pz Please note that a Mylar original of the revised final plat will be required after Staff approval and prior to the filing of the plat. If you have any questions or need additional information, please call me at 979.764.3570. Attachments: Staff review comments cc: Schultz Engineering, LLC via email: joeschultz84@verizon.net Case file no. 13-00900029 Home of Texas A&M University STAFF REVIEW COMMENTS NO. 2 Project: MURPHY SUBDIVISION (FP -MINOR) - 13-00900029 PLANNING 1. Revise the Certificate of the City Planner to remove the "Chairman" label under the signature bar and replace it with "City Planner" 2. Please note that you may be required to submit paid tax certificates if they are not current prior to the filing of your plat. Reviewed by: Teresa Rogers Date: March 6. 2013 NOTE: Any changes made to the plans, that have not been requested by the City of College Station, must be explained in your next transmittal letter and "bubbled" on your plans. Any additional changes on these plans that have not been pointed out to the City, will constitute a completely new review. 2 of 2 CITY OF COTIEGF. STATION Home ofTa&A6M Unio iV- 1101 Texas Avenue, P.O. Box 9960 College Station, Texas 77842 Phone 979.764.3570 / Fax 979.764.3496 MEMORANDUM March 6, 2013 TO: TMFIVE Properties, LLC via email: terrencerealtor@gmail.com FROM: Teresa Rogers, Staff Planner SUBJECT: MURPHY SUBDIVISION - Final Plat Staff reviewed the above -mentioned final plat as requested. The following page is a list of staff review comments detailing items that need to be addressed. If all comments have been addressed and the following information submitted on any Monday by 10:00 a.m., your project will be placed on the next available Planning and Zoning Commission meeting held in the City Hall Council Chambers. 1101 Texas Avenue. One (1) 24"x36" copy of the revised final plat; One (1) Mylar original of the revised final plat (required after Staff approval); Parkland Dedication for duplexes will be assessed prior to the issuance of building permits; and One (1) copy of the digital file of the final plat on diskette or e-mail to pdsdigitalsubmittal(cDcstx.gov. Upon receipt of the required documents for the Planning & Zoning meeting, your project will be considered formally filed with the City of College Station. Please note that this application will expire in 90 days from the date of this memo, if the applicant has not provided written response comments and revised documents to the Administrator that seek to address the staff review comments contained herein. Once your item has been scheduled for the P&Z meeting, the agenda and staff report can be accessed at the following web site on Monday the week of the P&Z meeting. http://www.csb(.gov/pz Please note that a Mylar original of the revised final plat will be required after Staff approval and prior to the filing of the plat. If you have any questions or need additional information, please call me at 979.764.3570. Attachments: Staff review comments cc: Schultz Engineering, LLC via email: joeschultz84@verizon.net Case file no. 13-00900029 Home of Texas A&M University STAFF REVIEW COMMENTS NO. 2 Project: MURPHY SUBDIVISION (FP -MINOR) - 13-00900029 PLANNING 1. Revise the Certificate of the City Planner to remove the "Chairman" label under the signature bar and replace it with "City Planner" 2. Please note that you may be required to submit paid tax certificates if they are not current prior to the filing of your plat. Reviewed by: Teresa Rogers Date: March 6, 2013 ENGINEERING COMMENTS NO. 2 1. (Repeat) A 10-ft PUE is required at the rear of the lots. Please move the proposed 10-ft PUE along the rear of lots 2 &3 to make it adjacent with the existing PUE. 2. FYI ... As a condition of approval, all existing structures which will encroach into newly created PUEs will need to be removed prior to the final plat being filed. Reviewed by: Erika Bridges Date: March 4, 2013 Home of Texas A&M University City of College Station Administrative Approval for Required Parkland Dedications of Less than Five Acres 1. Applicant Name: Terrence Murphy, TMFIVE Properties, LLC Address: 3091 University Drive East, Suite 230, College Station, TX 77802 Phone: (979) 703-1979 E-Mail: TerrenceRealtor2rpomail.com 2. Development Name: Murphy Subdivision Project #: 13-29 Development Location: 805 — 901 Montclair Avenue, College Station, TX 77840 3. Dwelling Units: 0 Single Family 3 Multi -family Units, located in Neighborhood Park Zone 6 0 Single Family 3 Multi -family Units, located in Community Park Zone B 4. Development Fees and Dedication Requirements: a. Land Dedication or Fee in Lieu of Land (Choose One): Neighborhood Community Total Single Family: One (1) acre per 117 DU's 0 ac One (1) acre per 128 DU's 0 ac = 0 ac Multi -family: One (1) acre per 117 DU's 0 ac One (1) acre per 128 DU's 0 ac = 0 ac Fee Paid in Lieu of Land Dedication Neighborhood WI M Community TOTAL = 0 Acres Single Family: @ $274.11 per DU $ 0 @ $250.11 per DU $ 0 Multi -family: @ $274.00 per DU $ 822.00 @ $250." per DU $ 750.00 _ $ 1,572.00 TOTAL (Neighborhood and Community) _ $ 1,572.00 b. Development Fee: Neighborhood Community Total Single Family @ $362.°° per DU $ 0 Single Family @ $375.11 per DU $ 0 = $ 0 Multi -family @ $362.11 per DU $ 1,086.00 Multi -family @ $750.11 per DU $ 2,250.00 = $ 3,336.00 TOTAL (Neighborhood and Community) _ $ 3,336.00 S. Comments: There are five existing units on three lots. This plat will create four lots and allow for the addition of three new units. The City of College Station agrees to accept: GRAND TOTAL (Neighborhood and Community) 3 Units x $1.636.00 = $ 4,908.00 Land Dedication 0 Name Date City of College Station Administrative Approval for Required Parkland Dedications of Less than Five Acres 1. Applicant Name: T ,cnoL Murohv. TMFJVE Properties. LLG Address: East Suite 230College Stslion TX 77&)2 Phone: (979t 703.1979 E-Mall:— TerrenceReaftwAgmei.aam 2. Development Name: Murphy Subdivision Project Development Location; 805 - 901 Montclair Avenue, College Slelion TX 77W 3. Dwelling Units: D Single Family 3 Wlb-family Un*s, located in Neighborhood Park Zone 8 __Q_ Single Family 3 Multi-lemily Units, ioeated in Community Park Zone __Ja_ 4. Development Fees and Dedication Requlremenla: t, Land Dedication or Fee in Lieu of Land (Chooea Onaj: Neighbottrcod Single Fes; One (1) acre per 117 Mrs 0 sc One (1) aae per 120 ors D ac - 0 ac Mulpi�family- One (1) acre per 117 We 0 me One (1) mete per 129 Mrs D tC = 0 ac —OR— Fee Paid In Llsu of Larm Dedication TOTAL = 0 Awe$ Neighborhood Community Sirgto FmmilY C S274 Do par Ou $ 0 @ 3250 L° per DU $ 0 - �_ 0 Muttl-family (MSZ74 °* per DU $ 922A0 @ 5250.m pw DU $ 750.00 f— 1,572.00 TOTAL (Nalghbomood mnd Community) 1,S7200 b. Development Fee: NeighborheaA Commun ty TTQ1W Single Fanny @ VMm per DU S 0 Single Family @ $373 °0 per DU € Q = S_ 0 k(u16-family Q3362.00perDU$1,0M.0D Multifamily S75D°° perDUS 2,250.00 .$ 3,336.09 TOTAL (Neighborfiood Md Cpmmunhy) .6 3,336-DO 5, Commerttt: There are five existing units An three lots. Th_y plat vnll create four lots and allow for the KWiti0n OT three new unite. The Glty of College Station agrees to accept: GRAND TOTAL (Neighborhood and Contmunily) a Units x $M36.00 = S 4,908.00 Land DedJcatlon 0